Livre 3 — Contrats spécifiques
Article 591
Texte légal (original thaï)
Comptes rendus Voir aussi Comptes rendus Conseils d'administration Comptes rendus Conseils d'administration ด้รู้อยู่แล้ Conseils d'administration Comptes rendus Comptes rendus
Texte intégral tiré de la Gazette royale / Bureau du Conseil d'État
traduction anglaise
Si le défaut ou le retard des travaux provient de la nature des matériaux fournis par le maître d'ouvrage ou des instructions données par celui-ci, l'entrepreneur n'est pas responsable, sauf s'il avait connaissance de l'inadéquation des matériaux ou du caractère inapproprié des instructions et qu'il n'en a pas informé le client.
This English translation is provided for reference only and has not yet been firm-verified. Always rely on the Thai original.
Annotation de l'entreprise
L'article 591 fait partie du Livre 3 (Contrats spécifiques) du Code civil et commercial thaïlandais. Cet article est en attente d'un commentaire officiel ; le texte de loi ci-dessus est tiré intégralement du site web du Bureau du Conseil d'État (OCS Krisdika), la traduction anglaise provenant du dépôt FAO/UN FAOLEX. En cas de procédure judiciaire, veuillez toujours vous référer au texte original thaïlandais.
Cited in 1 Supreme Court decisions (1967 to 1967)
Selected citing decisions
- Decision 484/2510 (1967)
This list is selected automatically, weighted towards judgments that turn on this section rather than ones that merely recite it when passing sentence. It has not yet been reviewed by the firm.
Counted across the firm's corpus of 83 652 Supreme Court decisions, 1921 to 2026. The count is complete; the stated year range trims rare outliers so it describes where the citations actually sit. These figures are computed by us and are not official court statistics.
Guides connexes sur ThaiLawOnline
Cite this section
-
Plain citation
Civil and Commercial Code, s. 591 (Thailand) -
Academic citation
Civil and Commercial Code (Thailand), s. 591. ThaiLawOnline, https://www.thailawonline.com/fr/thai-civil-code/section-591/ (accessed 8 août 2026). -
Thai citation
ป.พ.พ. มาตรา 591 -
Permalink
https://www.thailawonline.com/fr/thai-civil-code/section-591/ -
Embed on your site
<blockquote cite="https://www.thailawonline.com/fr/thai-civil-code/section-591/"><p>If the defect or the delay of the work originates from the nature of the material supplied by the employer, or from instruction given by him, the contractor is not liable, unless the contractor knew of the unfitness of the materials or the impropriety of…</p><footer>Civil and Commercial Code, s. 591 (Thailand) — <a href="https://www.thailawonline.com/fr/thai-civil-code/section-591/">ThaiLawOnline</a></footer></blockquote>
The Thai text is authoritative. The English is an unofficial translation by ThaiLawOnline, free to reuse with attribution.